Standard
UPDATE AVAILABLE
Track updates
AS 4906-2002
[Current]Minor works contract conditions (Principal administered)
This Standard is intended to be used for construct-only projects of a simple nature and of limited monetary value. It is not suitable for projects of a complex or long term nature or where a bill of quantities has been prepared. There is also no provision for seperable portions or selected subcontracts.
Published: 25/02/2002
Pages: 25
Table of contents
Cited references
Content history
Table of contents
Header
About this publication
Preface
1 Interpretation and construction of Contract
2 Nature of Contract
2.1 Performance and payment
2.2 Quantities
3 Security
3.1 Provision
3.2 Recourse
3.3 Reduction and release
3.4 Trusts and interest
4 Service of notices
5 Discrepancies
6 Assignment and subcontracting
6.1 Assignment
6.2 Subcontracting
7 Legislative requirements
8 Protection
9 Care of the work and reinstatement of damage
9.1 Care of WUC
9.2 Reinstatement
9.3 Excepted risks
10 Damage to persons and property other than WUC
10.1 Indemnity by Contractor
10.2 Indemnity by Principal
11 Insurance of the Works
12 Public liability insurance
13 Insurance of employees
14 Insurance provisions
14.1 Proof of insurance
14.2 Cross liability
15 Principal’s direction
16 Representatives
17 Site
18 Materials and work
18.1 Quality of material and work
18.2 Defective work
19 Programming and suspension
20 Time and progress
20.1 Progress
20.2 Claim
20.3 Extension of time
20.4 Practical completion
20.5 Liquidated damages
20.6 Delay damages
21 Defects liability
22 Variations
22.1 Directing variations
22.2 Pricing
23 Payment
23.1 Progress claims
23.2 Certificates
23.3 Final payment claim and certificate
23.4 Interest
24 Payment of workers and subcontractors
24.1 Workers and subcontractors
24.2 Withholding payment
25 Default or insolvency
25.1 Preservation of other rights
25.2 Contractor’s default
25.3 Principal’s notice to show cause
25.4 Principal’s rights
25.5 Take out
25.6 Adjustment on completion of work taken out
25.7 Principal’s default
25.8 Contractor’s notice to show cause
25.9 Contractor’s rights
25.10 Termination
25.11 Insolvency
26 Notification of claims
26.1 Communication of claims
26.2 Liability for failure to communicate
26.3 Resolution
27 Dispute resolution
27.1 Notice of dispute
27.2 Conference
27.3 Arbitration
27.4 Summary relief
Part A
Part B
† Index
Amendment control sheet
Cited references in this standard
$145.75
AUD
Inclusive of GST
Available formats
Web Reader
Licence:
1 user
Total
$145.75
